Australia: EPC Contracts In The Australian Renewable Energy Sector – Wind Farms, part 2

Last Updated: 28 October 2012
Article by Damian McNair
This article is part of a series: Click EPC Contracts In The Australian Renewable Energy Sector – Wind Farms, part 1 for the previous article.


A bankable contract is a contract with a risk allocation between the contractor and the project company that satisfies the lenders. Lenders focus on the ability (or more particularly the lack thereof) of the contractor to claim additional costs and/or extensions of time as well as the security provided by the contractor for its performance. The less comfortable the lenders are with these provisions, the greater amount of equity support the sponsors will have to provide. In addition, lenders will have to be satisfied as to the technical risk. Obviously price is also a consideration, but that is usually considered separately to the bankability of the contract because the contract price (or more accurately the capital cost of the wind farm) goes more directly to the bankability of the project as a whole.

Before examining the requirements for bankability, it is worth briefly considering the appropriate financing structures and lending institutions. The most common form of financing for infrastructure projects is project financing. Project financing is a generic term that refers to financing secured only by the assets of the project itself. Therefore, the revenue generated by the project must be sufficient to support the financing. Project financing is also often referred to as either "non-recourse" financing or "limited recourse" financing.

The terms "non-recourse" and "limited recourse" are often used interchangeably, however they mean different things. "Non-recourse" means there is no recourse to the project sponsors at all and "limited recourse" means, as the name suggests, there is limited recourse to the sponsors. The recourse is limited both in terms of when it can occur and how much the sponsors are forced to contribute. In practice, true non-recourse financing is rare. In most projects the sponsors will be obliged to contribute additional equity in certain defined situations.

Traditionally project financing was provided by commercial lenders. However, as projects became more complex and financial markets more sophisticated, project finance also developed. Whilst commercial lenders still provide finance, governments now also provide financing either through export credit agencies 22 or trans or multinational organisations like the World Bank, the Asian Development Bank and European Bank for Reconstruction and Development. In addition, as well as bank borrowings sponsors are also using more sophisticated products like credit wrapped bonds, securitisation of future cash flows and political risk insurance to provide a portion of the necessary finance.

In assessing bankability, lenders will look at a range of factors and assess a contract as a whole. Therefore, in isolation it is difficult to state whether one approach is or is not bankable. However, generally speaking the lenders will require the following:

  • A fixed completion date
  • A fixed completion price
  • No or limited technology risk
  • Output guarantees
  • Liquidated damages for both delay and performance
  • Security from the contractor and/or its parent
  • Large caps on liability (ideally, there would be no caps on liability, however, given the nature of EPC contracting and the risks to the contractors involved there are almost always caps on liability)
  • Restrictions on the ability of the contractor to claim extensions of time and additional costs.

An EPC contract delivers all of the requirements listed above in one integrated package. This is one of the major reasons why they are the predominant form of construction contract used on large-scale project financed infrastructure projects. Again, lenders have become comfortable with the interface risk in a split EPC structure and will focus on the remedies for underperformance in the WOM.

Sponsor support

In certain cases, it may be necessary to provide sponsor support to strengthen the capacity of the project company to satisfy its obligations to the banks and to have a "bankable" project. Forms of sponsor support may include equity subscription agreements (base and standby equity), completion guarantees of whole or part of the debt until the project commences commercial operation, bank guarantees to support completion guarantee and cost overrun guarantees/facility. Completion guarantees, for example, ensure that the lenders will be paid back a set amount if the facility does not reach completion or the repayment of scheduled debt service, of principal plus interest, if completion is delayed. Other forms of support may be incorporated where the sponsor is a party to a key project contract (such as a construction contract, O&M agreement or offtake agreement) by requiring the sponsor to provide additional guarantee letters of credit or corporate support to underpin the project.


The key clauses in any construction contract are those that impact on time, cost and quality.

The same is true of EPC contracts. However, EPC contracts tend to deal with issues with greater sophistication than other types of construction contracts. This is because, as mentioned above, an EPC contract is designed to satisfy the lenders? requirements for bankability.

EPC contracts provide for:

A single point of responsibility. The contractor is responsible for all design, engineering, procurement, construction, commissioning and testing activities. Therefore, if any problems occur the project company need only look to one party – the contractor – to both fix the problem and provide compensation. As a result, if the contractor is a consortium comprising several entities, the EPC contract must state that those entities are jointly and severally liable to the project company.

A fixed contract price. Risk of cost overruns and the benefit of any cost savings are to the contractor?s account. The contractor usually has a limited ability to claim additional money, which is limited to circumstances where the project company has delayed the contractor or has ordered variations to the works.

A fixed completion date. EPC contracts include a guaranteed completion date that is either a fixed date or a fixed period after the commencement of the EPC contract. If this date is not met the contractor is liable for Delay Liquidated Damages (DLDs). DLDs are designed to compensate the project company for loss and damage suffered as a result of late completion of the wind farm. To be enforceable in common law jurisdictions 23 , DLDs must be a genuine pre-estimate of the loss or damage that the project company will suffer if the wind farm is not completed by the target completion date. The genuine preestimate is determined by reference to the time the contract was entered into.

DLDs are usually expressed as a rate per day, which represents the estimated extra costs incurred (such as extra insurance, supervision fees and financing charges) and losses suffered (revenue forgone) for each day of delay.

In addition, the EPC contract must provide for the contractor to be granted an extension of time when it is delayed by the acts or omissions of the project company. The extension of time mechanism and reasons why it must be included are discussed later.

Performance guarantees. The project company?s revenue will be earned by operating the wind farm. Therefore, it is vital that the wind farm performs as required in terms of output and reliability. Therefore, EPC contracts contain performance guarantees backed by Performance Liquidated Damages (PLDs), payable by the contractor if it fails to meet the performance guarantees. These performance guarantees usually comprise a guaranteed power curve and an availability guarantee guaranteeing the level of generation of electricity 24 .

PLDs must also be a genuine pre-estimate of the loss and damage that the project company will suffer over the life of the project if the wind farm does not achieve the specified performance guarantees. As with DLDs, the genuine pre-estimate is determined by reference to the time the contract was signed.

PLDs are usually a Net Present Value (NPV) (less expenses) calculation of the revenue forgone over the life of the project.

For example, if the output of the plant is 5 MW less than the specification, the PLDs are designed to compensate the project company for the revenue forgone over the life of the project by being unable to sell that 5 MW.

PLDs and the performance guarantee regime and its interface with the DLDs and the delay regime is discussed in more detail below.

Caps on liability. As mentioned above, most EPC contractors will not, as a matter of company policy, enter into contracts with unlimited liability. Therefore, EPC contracts for power projects cap the contractor?s liability at a percentage of the contract price. This varies from project to project, however, an overall liability cap of 100% of the contract price is common. In addition, there are normally sub-caps on the contractor?s liquidated damages liability. For example, DLDs and PLDs might each be capped at 20% of the contract price, with an overall cap on both types of liquidated damages of 30% of the contract price.

There will also likely be a prohibition on the claiming of consequential damages. Put simply, consequential damages are those damages that do not flow directly from a breach of contract, but which were in the reasonable contemplation of the parties at the time the contract was entered into. This used to mean heads of damage like loss of profit. However, loss of profit is now usually recognised as a direct loss on project financed projects and, therefore, would be recoverable under a contract containing a standard exclusion of consequential loss clause. Nonetheless, care should be taken to state explicitly that liquidated damages can include elements of consequential damages. Given the rate of liquidated damages is pre-agreed, most contractors will not object to this exception.

In relation to both caps on liability and exclusion of liability, it is common for there to be some exceptions. The exceptions may apply to either or both the cap on liability and the prohibition on claiming consequential losses. The exceptions themselves are often project specific, however, some common examples include in cases of fraud or wilful misconduct, in situations where the minimum performance guarantees have not been met and the cap on delay liquidated damages has been reached and breaches of the intellectual property warranties.

Security. It is standard for the contractor to provide performance security to protect the project company if the contractor does not comply with its obligations under the EPC contract. The security takes a number of forms including:

  • A bank guarantee for a percentage, normally in the range of 5–15%, of the contract price. The actual percentage will depend on a number of factors including the other security available to the project company, the payment schedule (because the greater the percentage of the contract price unpaid by the project company at the time it is most likely to draw on security, ie to satisfy DLD and PLD obligations the smaller the bank guarantee can be), the identity of the contractor and the risk of it not properly performing its obligations, the price of the bank guarantee and the extent of the technology risk
  • Retention, ie withholding a percentage (usually 5%–10%) of each payment. Provision is often made to replace retention monies with a bank guarantee (sometimes referred to as a retention guarantee (bond))
  • Advance payment guarantee, if an advance payment is made
  • A parent company guarantee - this is a guarantee from the ultimate parent (or other suitable related entity) of the contractor, which provides that it will perform the contractor?s obligations if, for whatever reason, the contractor does not perform.

Variations. The project company has the right to order variations and agree to variations suggested by the contractor. If the project company wants the right to omit works either in their entirety or to be able to engage a different contractor, this must be stated specifically. In addition, a properly drafted variations clause should make provision for how the price of a variation is to be determined. In the event the parties do not reach agreement on the price of a variation, the project company or its representative should be able to determine the price. This determination is subject to the dispute resolution provisions. In addition, the variations clause should detail how the impact, if any, on the performance guarantees is to be treated. For some larger variations the project company may also wish to receive additional security. If so, this must also be dealt within the variations clause.

Defects liability. The contractor is usually obliged to repair defects that occur in the 12 to 24 months following completion of the performance testing. Defects liability clauses can be tiered, ie the clause can provide for one period for the entire wind farm and a second, extended period for more critical items.

Intellectual property. The contractor warrants that it has rights to all the intellectual property used in the execution of the works and indemnifies the project company if any third parties? intellectual property rights are infringed.

Force majeure. The parties are excused from performing their obligations if a force majeure event occurs. This is discussed in more detail below

Suspension. The project company usually has the right to suspend the works.

Termination. This sets out the contractual termination rights of both parties. The contractor usually has very limited contractual termination rights. These rights are limited to the right to terminate for non-payment or for prolonged suspension or prolonged force majeure and will be further limited by the tripartite or direct agreement between the project company, the lenders and the contractor. The project company will have more extensive contractual termination rights. They will usually include the ability to terminate immediately for certain major breaches or if the contractor becomes insolvent and the right to terminate after a cure period for other breaches. In addition, the project company may have a right to terminate for convenience. It is likely the project company?s ability to exercise its termination rights will also be limited by the terms of the financing agreements.

Performance specification. Unlike a traditional construction contract, an EPC contract usually contains a performance specification. The performance specification details the performance criteria that the contractor must meet. However, it does not dictate how they must be met. This is left to the contractor to determine. A delicate balance must be maintained. The specification must be detailed enough to ensure the project company knows what it is contracting to receive but not so detailed that if problems arise the contractor can argue they are not its responsibility.

Whilst there are, as described above, numerous advantages to using an EPC contract, there are some disadvantages. These include the fact that it can result in a higher contract price than alternative contractual structures. This higher price is a result of a number of factors not least of which is the allocation of almost all the construction risk to the contractor. This has a number of consequences, one of which is that the contractor will have to factor into its price the cost of absorbing those risks. This will result in the contractor building contingencies into the contract price for events that are unforeseeable and/or unlikely to occur. If those contingencies were not included, the contract price would be lower. However, the project company would bear more of the risk of those unlikely or unforeseeable events. Sponsors have to determine, in the context of their particular project, whether the increased price is worth paying.

As a result, sponsors and their advisors must critically examine the risk allocation on every project. Risk allocation should not be an automatic process. Instead, the project company should allocate risk in a sophisticated way that delivers the most efficient result. For example, if a project is being undertaken in an area with unknown geology and without the time to undertake a proper geotechnical survey, the project company may be best served by bearing the site condition risk itself as it will mean the contractor does not have to price a contingency it has no way of quantifying. This approach can lower the risk premium paid by the project company. Alternatively, the opposite may be true. The project company may wish to pay for the contingency in return for passing off the risk which quantifies and caps its exposure. This type of analysis must be undertaken on all major risks prior to going out to tender.

Another consequence of the risk allocation is the fact that there are relatively few construction companies that can and are willing to enter into EPC contracts. As mentioned in the introduction, some bad publicity and a tightening insurance market have further reduced the pool of potential EPC contractors. The scarcity of EPC contractors can also result in relatively high contract prices.

Another major disadvantage of an EPC contract becomes evident when problems occur during construction. In return for receiving a guaranteed price and a guaranteed completion date, the project company cedes most of the day-to-day control over the construction. Therefore, project companies have limited ability to intervene when problems occur during construction. The more a project company interferes, the greater the likelihood of the contractor claiming additional time and costs. In addition, interference by the project company will make it substantially easier for contractors to defeat claims for liquidated damages and defective works.

Obviously, ensuring the project is completed satisfactorily is usually more important than protecting the integrity of the contractual structure. However, if a project company interferes with the execution of the works, in most circumstances it will have the worst of both worlds. It will have a contract that exposesit to liability for time and costs incurred as a result of its interference without any corresponding ability to hold the contractor liable for delays in completion or defective performance. The same problems occur even where the EPC contract is drafted to give the project company the ability to intervene. In many circumstances, regardless of the actual drafting, if the project company becomes involved in determining how the contractor executes the works, then the contractor executes the works then the contractor will be able to argue that it is not liable for either delayed or defective performance.

As a result, it is vitally important that great care is taken in selecting the contractor and in ensuring the contractor has sufficient knowledge and expertise to execute the works. Given the significant monetary value of EPC contracts, and the potential adverse consequences if problems occur during construction, the lowest price should not be the only factor used when selecting contractors.


The basic split structure involves splitting the EPC contract into an onshore construction contract and an offshore supply contract 25 .

There are two main reasons for using a split contract. The first is because it can result in a lower contract price as it allows the contractor to make savings in relation to onshore taxes; in particular on indirect and corporate taxes in the onshore jurisdiction. The second is because it may reduce the cost of complying with local licensing regulations by having more of the works, particularly the design works, undertaken offshore. In addition, in some countries which impose restrictions on who can carry out certain activities like engineering and design services, splitting the EPC contract can also be advantageous because it can make it easier to repatriate profits.

As mentioned above, the benefits in splitting an EPC contract for tax and licensing reasons primarily arise in certain countries in Asia; there has not, nor is there likely to be given the climatic and geographical conditions, been a project financed wind farm project in Asia. However, a split EPC contractual structure arises in another context in wind farm projects. The manufacturers of the turbines have successfully avoided taking the turnkey responsibility by entering into a supply contract and a balance of plant contract (ie the foundation works, civils and erection etc.) instead of an EPC contract.

There are risks to the project company in this structure. This mainly arises because of the derogation from the principle of single point of responsibility.

Unlike a standard EPC contract, the project company cannot look only to a single contractor to satisfy all the contractual obligations (in particular, design, construction and performance). Under a split structure, there are at least two entities with those obligations. Therefore, a third agreement, a wrap-around guarantee 26 , is often used to deliver a single point of responsibility despite the split.

Under a wrap-around guarantee, an entity, usually either the offshore supplier or the parent company of the contracting entities, guarantees the obligations of both contractors. This delivers a single point of responsibility to the project company and the lenders. However, that agreement is not relevant where the manufacturer of the turbines and the balance of plant contractor are separate entities and neither company will take the single point of responsibility under the wrap-around guarantee. Accordingly, the lenders will want to be satisfied that the interface issues are dealt with in the absence of a single point of responsibility.


General interface issues

As noted in the earlier section above, an EPC contract is one of a suite of agreements necessary to develop a wind farm project. Therefore, it is vital that the EPC contract properly interfaces with those other agreements. In particular, care should be taken to ensure the following issues interface properly:

  • Commencement and completion dates
  • Liquidated damages amounts and trigger points
  • Caps on liability
  • Indemnities
  • Entitlements to extensions of time
  • Insurance
  • Force majeure
  • Intellectual property.

Obviously, not all these issues will be relevant for all agreements. In addition to these general interface issues that apply to most types of projects, there are also power project issues that must be considered. These issues are mainly concerned with the need to burn fuel and export power. They are discussed in more detail below 27 .

Those major renewable energy specific interface issues are:

  • Access for the contractor to the transmission grid to allow timely completion of construction, commissioning and testing (grid access)
  • Consistency of commissioning and testing regimes
  • Interface issues between the relevant government agencies and system operator and the contractor. In particular, whilst the project company must maintain a long term/comfortable relationship with either the government or the system operator, the contractor does not.


22 Export credit agencies are bodies that provide finance on the condition that the funds are used to purchase equipment manufactured in the country of the export credit agency.
23 For the purposes of this paper, we have assumed the EPC contract will be governed by the law of a common law jurisdiction. Where there are differences between jurisdictions we have adopted the English law approach. Therefore, if an EPC contract is governed by a law other than English law you will need to seek advice from local counsel to ensure the contract is enforceable in the relevant jurisdiction. For example, in both the PRC and Malaysia liquidated damages amounts specified in a contract may be subsequently altered by a court. If a party can show that the liquidated damages amounts will either under or in some cases over compensate a party the court can adjust the damages payable so they more accurately reflect the actual damage suffered by a party.
24 On projects where the supplier or manufacturer of the wind turbine generator is appointed as an operator of the wind farm for a fixed duration, it is not unusual for the availability guarantees to be provided by the operator under the O&M Agreement. This is sometimes referred to as a warranty, operations and maintenance agreement ("WOM"). Refer to the following section for a discussion on Split EPC contracts.
25 For a more detailed discussion on split EPC contracts refer to the DLA Piper International Best Practice in Project and Construction Agreements paper entitled "EPC contracts in the Power Sector" dated April 2004. We have also prepared a paper that deals with the variations and complications in split EPC contracts. You should consult that paper, or ask us for a copy, if you want more information on this topic.
26 This is also called a Co-ordination Agreement, an Administration Agreement or an Umbrella Deed.
27 This discussion assumes the project company will be entering into either a PPA or a Tolling Agreement. However, some of these issues will also be relevant if the project company is entering into hedging agreements for a merchant project. For example, those hedge agreements will likely mandate a date by which the power station must be capable of commercial operation. Failure to comply with this requirement will incur monetary liability. Similarly there may be availability requirements and certain performance guarantees imposed by the hedge. These requirements must be flowed through to the EPC contract.

© DLA Piper

This publication is intended as a general overview and discussion of the subjects dealt with. It is not intended to be, and should not used as, a substitute for taking legal advice in any specific situation. DLA Piper Australia will accept no responsibility for any actions taken or not taken on the basis of this publication.

DLA Piper Australia is part of DLA Piper, a global law firm, operating through various separate and distinct legal entities. For further information, please refer to

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

This article is part of a series: Click EPC Contracts In The Australian Renewable Energy Sector – Wind Farms, part 1 for the previous article.
This article is part of a series: Click EPC Contracts In The Australian Renewable Energy Sector – Wind Farms, part 3 for the next article.
Similar Articles
Relevancy Powered by MondaqAI
Some comments from our readers…
“The articles are extremely timely and highly applicable”
“I often find critical information not available elsewhere”
“As in-house counsel, Mondaq’s service is of great value”

Related Topics
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions