UK: FIDIC, Force Majeure, Exceptional Events And The "But For" Test

Under the 2017 edition of the FIDIC Rainbow Suite, clause 19 which was headed "force majeure" has been replaced by clause 18, "exceptional events". This is an interesting change; the term "force majeure" is typically provided for within most civil codes, whereas it is not a term of art under the common law.

The essential scheme of the FIDIC Form has remained unchanged, namely for something to amount to an exceptional event, there must be an event which is beyond the control of the party affected and which the party affected could neither have foreseen or provided against before entering into the contract nor avoided once it had arisen. The event must also not be the fault of the other party. Under sub-clause 18.2 of the new second edition, the Contractor must give a Notice, in the proper form, within 14 days of becoming aware, or of the date when it should have become aware, of the exceptional event. Subject to this, under sub-cause 18.3, the Contractor may be entitled to an extension of time and/or recovery of costs incurred as a result. If the exceptional event is prolonged, the option of termination may arise.

A question that might arise is whether a Contractor can only rely on this type of clause in circumstances where it can show that it would have been able to perform the contract "but for" the exceptional event, or whether it is enough to show that the event in question prevented the Contractor from performing its obligations under the Contract..This question was considered by Mr Justice Teare in the case of Classic Maritime Inc. v Limbungan Makmur SDN BHD & Anr 1

On 5 November 2015, the Fundao dam, in the industrial complex of Germano in Brazil where iron ore is mined, burst. Iron ore production immediately stopped and shipments were suspended. Classic had entered into a long-term contract of affreightment (the "COA") for the carriage of iron ore pellets from Brazil to Malaysia. Limbungan was the charterer under the COA. Limbungan relied upon the dam burst as a force majeure event excusing it from liability for failing to provide cargoes of iron ore pellets for shipment from Brazil to Malaysia. Classic disagreed and claimed damages for breach of contract.

Clause 32 of the COA provided as follows:


Neither the vessel, her master or Owners, nor the Charterers, Shippers or Receivers shall be Responsible for loss of or damage to, or failure to supply, load, discharge or deliver the cargo resulting from: Act of God . . . floods . . . accidents at the mine or Production facility . . . or any other causes beyond the Owners' Charterers' Shippers' or Receivers' control; always provided that such events directly affect the performance of either party under this Charter Party . . ."

Mr Justice Teare noted that the clause was described as "a force majeure clause" though as with the new FIDIC Contract, that phrase is not used in it. The Judge thought it was better described as an "exceptions clause". There was no dispute that the dam burst was an "accident at the mine". Limbungan said that as a result of the dam burst, it found itself unable to supply cargoes for shipment under the COA. Classic said that the collapse of the dam had no causative effect on the charterer because the shipments would not have been performed even if there had not been a dam burst.

Classic submitted that the effect of clause 32 was to impose a "but for" test of causation. Since the clause required Limbungan's failure to supply a cargo to "result from" the force majeure event (in this case the dam burst), and also for that event to "directly affect" the performance of Limbungan's obligation, Limbungan was required to prove that, but for the dam burst, it could and would have performed the COA in accordance with its terms.

Limbungan disagreed, saying that whilst clause 32 imposed a causation requirement in the sense that it had to be shown that the dam burst rendered performance of Limbungan's obligations impossible, it was not necessary for Limbungan to show that but for the dam burst it would have performed its obligations.

The Judge summarised the position in this way. Does the "but for" test have to be satisfied in a force majeure or exceptions clause which does not cancel the contract for the future, like a frustration clause, but provides a defence to a claim in damages for breach of the contract? The Judge felt that there was "an important difference" between a contractual frustration clause and what he had termed an exceptions clause. There was a difference between clauses which result in the discharge of a contract and the COA here:

"A contractual frustration clause, like the doctrine of frustration, is concerned with the effect of an event upon a contract for the future. It operates to bring the contract, or what remains of it, to an end so that thereafter the parties have no obligations to perform. An exceptions clause is concerned with whether or not a party is exempted from liability for a breach of contract at a time when the contract remained in existence and was the source of contractual obligations. It is understandable that a contractual frustration clause should be construed as not requiring satisfaction of the 'but for' test because that is not required in a case of frustration."

However, the "exceptions" in the contract here were different. It is not concerned with writing into a contract what is to happen in the event of a frustrating event. It is concerned with excusing a party from liability for a breach that has occurred. As the Judge said, in these circumstances, it would be a "surprise" that a party could be excused from liability where, although an event within the clause had occurred which made performance impossible, the party would not have performed in any event for different reasons. Therefore clause 32 required Limbungan to show that but for the dam burst the cargo would have been supplied.

Therefore the court went on to consider whether, but for the dam burst, Limbungan would have supplied cargo for the voyages which were the subject of the present claim. This was a factual issue. On the facts, the Judge doubted whether, but for the dam burst, Limbungan would have been able and willing to supply cargoes for shipment pursuant to the COA with Classic. Limbungan were unable to demonstrate that their inability to fulfil the COA was "resulting from" or "directly affected by" the dam burst. This was because Limbungan had not fulfilled the two shipments prior to the dam burst, and at the time of the dam burst it appeared unable and/or unwilling to supply cargoes for shipment pursuant to the COA.


When it came to assessing quantum, Limbungan said substantial damages were not recoverable because, even if Limbungan had been able and willing to ship the cargoes but for the dam burst, Classic would not have been entitled to substantial damages because the dam burst would in fact have prevented Limbungan from shipping any iron ore pellets. Classic described this as "an impermissible sleight of hand", from not being ready to perform the COA when liability was being assessed to being ready to perform when damages were being assessed. The Judge disagreed with Classic's approach noting that the recoverability of substantial damages depended upon the compensatory principle and therefore upon a comparison between the position of Classic as a result of the breach and the position it would have been in had Limbungan performed its obligations. Here, if, but for the dam burst, Limbungan had been able and willing to ship the five cargoes, no cargoes would in fact have been shipped because of the dam burst and the dam burst would, in that event, have excused Limbungan from its failure to make the required shipments.

So, contrary to the approach on liability, clause 32 of the COA worked in Limbungan's favour as far as quantum was concerned.


The dispute between Classic and Limbungan related to the performance of the COA. Did clause 32 set out circumstances which might excuse Limbungan from their breach of contract? In coming to the decision he did, Mr Justice Teare seemed to accept that there was a difference between clauses which result in the discharge of a contract (which did not apply the "but for" test) and the COA here, which exempted a party from liability for non-performance. Therefore it is likely that the "but for" test will apply, under English Law, to other similar "force majeure-type"clauses which merely exempt parties from liability for non-performance.

However, as noted above, whilst clause 18 of the FIDIC Form primarily deals with the effect on performance of an exceptional event, it does also potentially provide for termination. Mr Justice Teare's approach did not deal with this type of contract, so under common law there still may be a conflict about whether or not the "but for" approach to liability adopted in the Classic case would apply. However, parties alleging force majeure will no doubt be called upon to show that they would have been able to perform had the force majeure event not occurred.


1. [2018] EWHC 2389 (Comm).

This article is taken from Fenwick Elliott's 2017/2018 Annual Review. To read further articles go to Fenwick Elliott Annual Review 2018/2019

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

Similar Articles
Relevancy Powered by MondaqAI
In association with
Related Topics
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions