UK: What Type Of Defect Can Prevent "Practical Completion"?

Last Updated: 27 June 2019
Article by Iain Drummond

What type of defect can prevent "practical completion"?

In Mears Ltd v Costplan Services (South East) Ltd & Ors 2019 EWCA Civ 502, the Court of Appeal provided guidance on the meaning of "Practical Completion" for the first time in 50 years. But is the position any clearer?


Mears, a provider of student housing, entered into an agreement for lease ("AFL") for a 21-year lease of two blocks of student accommodation to be constructed in Plymouth. Costplan was appointed as Employer's Agent. Under the terms of the AFL, the lease would become complete within five days of the blocks' practical completion ("PC"). If PC did not occur before the longstop date, Mears were entitled to terminate the lease.

In the event, the works were significantly delayed, and it transpired that there were various defects in the blocks, including that some of the rooms had been built more than 3% smaller than had been stipulated in the AFL. The maximum tolerance was 3%, as stated in Clause 6.2.1 of the AFL:

"6.2 – The Landlord shall not make any variations to the Landlord's Works or Building Documents which...

6.2.1 – materially affect the size (and a reduction of more than 3% of the size of any distinct area shown upon the Building Documents shall be deemed material), layout or appearance of the Property..."

Mears argued that, since several rooms had been built smaller than the 3% tolerance, there could be no PC. This meant PC not occurring by the longstop date, which entitled Mears to terminate the contract. In determining the dispute, the court had to examine whether or not PC had occurred.


Mears sought a declaration that PC could not be achieved where there were material or substantial defects. At first instance in the Technology and Construction Court, the court declined to grant this declaration. Although accepting that 56 rooms had been constructed in breach of the 3% tolerance range, the court held that the failure to construct the rooms within the 3% size tolerance was not a sufficiently material or substantial breach of the AFL to enable Mears to terminate due to PC not being achieved. The court held that PC depends on the extent of work done but also its quality; thus patent defects can prevent PC occurring, but this depends on the nature, extent and consequence of the disconformity, and even an irremediable breach may not prevent PC occurring.

Mears appealed the decision, on the basis that the 3% tolerance was expressly stated in the AFL as a "material" breach, which meant that PC could not occur and Mears should be able to terminate the contract. However, the appeal was dismissed, and the decision at first instance was upheld.  

The court agreed that Mears' statement that PC could not be achieved whilst there were material and substantial defects was "relatively uncontroversial". However, whether the existence of defects will prevent PC occurring is a matter of 'fact and degree', and a defect that is 'trifling in its extent or consequence' may not do so.  The fact that the defect in question is irremediable is irrelevant to this.

Specific guidance on PC

Lord Justice Coulson's judgement provides helpful guidance on PC in general. He said: 

  • PC is itself difficult to define and there are no hard and fast rules.
  • The existence of a latent defect will not prevent PC, because by its nature it is unknown.
  • It makes no difference whether the 'defect' involves an item of work not yet completed or one that has been completed but is defective; these are treated in the same way.
  • The existence of patent defects will be sufficient to prevent PC, save where they are trifling in nature, extent or effect.
  • The ability to use the works as intended may be a factor in considering whether a patent defect is trifling (for example, in this case the fact that the rooms were 3% smaller did not prevent the rooms from being used as student accommodation). However, this will not necessarily be determinative as to the position on PC.
  • The mere fact that a defect is irremediable does not mean the works are not practically complete. The question remains whether the defect is trifling.


This case provides useful guidance on PC, which is a term often not defined in construction contracts. The important point is that a patent defect may prevent PC, in the same way as incomplete work, but not if that defect is trifling, which will be a matter of 'fact and degree' depending on the nature, extent or consequence of the defect. 

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

In association with
Related Topics
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions