United States: Construction Claim Notice Travesty -Hope On The Horizon?

Last Updated: September 20 2018
Article by Henry L. Goldberg

Many of you who follow our Construction Law Alert know of the acronym I derisively coined on behalf of the industry, namely "COFED" (for "Contractor Forfeiture Enhancement Device"). It refers to the epidemic of wholly unfair and unnecessary contractual notice provisions in public (and increasingly) private sector construction contracts.

The term COFED has become synonymous with public owner disinterest in fundamental fairness in construction contracting and with the resulting contractor and subcontractor forfeiture of extremely valuable contract claims. Should a multi- million dollar claim be forfeited for want of an unnecessary 10 day or 30 day notice? Are these notices even used by contracting agencies?

The extent of outrageous COFEDs in construction contracts today had led to proposed reform legislation. I had the privilege of participating in the origination and drafting of the legislative bills designed to address this problem. The proposed new legislation would have outlawed COFEDs in public construction in New York.

The concept gained wide acceptance in Albany, with the bill passing unanimously in the Assembly and in the Senate by all but four votes! Regretfully, however, the passed bills were ultimately vetoed by Governor Cuomo after sitting on it for six months.

Such near legislative success (particularly for a first attempt!) was in large part due to a unified and truly statewide coalition of construction industry-based trade associations, which effectively mobilized in support of a legislative prohibition of COFEDs in public construction.

Now it appears that New York courts, which have been completely complicit in their strict enforcement of COFED-type notice provisions, may be beginning to reconsider the harshness of their prior decisions. Recently (6/15/18), a New York appellate court found the outrageous circumstances of a particular COFED unenforceable. This was after the lower (trial) court in the case had already dismissed the contractor's case for its alleged failure to strictly comply with a

COFED requirement that all notices be verified (i.e. sworn to).

In this potentially landmark case, the public agency's General Conditions had stated:

Any decision or determination of the Consultant, Owner or Owner's Representative shall be final, binding and conclusive on the Contractor unless the Contractor shall, within ten (10) working days after said decision, make and deliver to the Owner a written verified statement of the Contractor's contention that said decision is contrary to a provision of the Contract.

The public agency had challenged the claimant's entitlement to additional payment for 56 specific change orders. It argued that the contractor completely waived its right to seek additional payment by violating the aforementioned COFED by failing to verify its claim.

Interestingly, both the contractor and the government's court papers were "devoid of material factual disputes" regarding the actual performance of the contractor under the terms of the contract. The public agency simply argued that the plaintiff waived its rights to its claims by allegedly failing to strictly comply with the verification provision set forth in the public contract. Stripped to the essentials, the public agency shamefully sought to dismiss the claimant's entire claim merely for its failure to submit its extra work request in "verified" form. In other words, because the contractor did not swear under oath to the validity of all of its claim, the entire claim was sought to be, and was, dismissed.

The trial court had also pointed out, as purported justification for its harsh decision, that NYC-based appellate courts had consistently dismissed contractor claims for extra work payments where a contractor failed to strictly comply with COFED-like notice and other reporting requirements.

In fact, the trial court pointed out in justification for its decision in this case that in yet another, earlier, New York appellate decision, the appellate court had faced the very same absence-of-verification issue and held that failure to "verify" all requests for additional payment constituted a waiver and resulted in a forfeiture of all rights by the contractor.

However, in the recent appellate decision of June 5, 2018 discussed herein, the contractor reasonably argued that it should not be severely penalized for simply failing to submit its notice to the agency in "verified" form. There was no allegation that the claim documents were in any way inaccurate.

Although reprehensible, the trial court's original decision of May 8, 2017 was basically "correct" given the current obnoxious state of the law. The June 2018 appellate court's reversal of the trial court's decision appears to be an outlier, and inconsistent with prior holdings of the very same appellate court.

For its part, the appellate court's June 5, 2018 decision was as interesting, as it was brief. It stated that:

It is undisputed that plaintiff failed to satisfy a condition precedent to recovering disputed costs for extra work on which defendant forced price reductions. Although contractor gave detailed written statements contesting [Owner's] determinations of the fair and reasonable value of the extra work... it failed to give verified statements pursuant to the contract's General Conditions.

The appellate court further noted that:

[The agency] does not argue that plaintiff failed to document the costs of the claimed extra work, to provide timely notice of its claims for extra work, or to provide timely notice of its objections to defendant's rejections of, and price reductions on, the claimed extra work.

The appellate court also observed that the agency did not contend, other than in "conclusory terms," that plaintiff's failure to submit verified written notices was in any way prejudicial to it.

Finally, the appellate court pointed out that the cases upon which the public agency relied in court did not consider whether the failure to strictly comply with the condition precedent of verified notice should be excused to avoid a "disproportionate forfeiture" under circumstances where the noncompliance was de minimis and the defendant-public agency had shown no prejudice.

MH&H Commentary

It's hard to explain why this intermediate appellate court "found its conscience" in this case. As stated, this very same appellate court has repeatedly enforced hyper- strict enforcement of COFED notice provisions. Was it simply unable to reconcile how far the pendulum had swung in favor of public agencies in their blind enforcement of COFED's? The appellate court's decision found the failure to verify the claim notices an inconsequential and de minimis noncompliance, with no resulting prejudice to the agency specifically alleged.

Under such extraordinary facts, and despite the well settled law, this particular intermediate appellate court, at this particular time, based on these facts, could not in good conscious enforce the COFED involved. Is this appellate decision establishing a "lack of prejudice" and/or a "de minimis/inconsequential noncompliance" exception to the enforcement of COFEDs? Will "disproportionate forfeiture" be a new litigated concept for consideration?

What the future holds for this sorry state of affairs, and this outlier case, remains to be seen. For now, the industry must continue its legislative reform efforts. COFEDs, after all, challenge the very survival of contractors and subcontractors. There is no assurance that other courts, or this court, will in the future do the right thing in confronting COFED abuse.

Have you lost a valuable claim against a public agency due to a COFED? Is the public agency against which you asserted a valuable claim, asserting a COFED as a bargaining tool for you to substantially waive your valuable rights? This appellate case raises the hope that in the right hands, and under the right circumstances, COFEDS can be successfully challenged.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions