Given the recent devastating floods in Queensland, force majeure clauses in project agreements will become more pertinent. The amount of time spent negotiating these clauses is often minimal, with the general assumption that the risk will not affect companies/individuals and that the clause is a legal necessity and does not impact risk allocation under the contract. Recent events exemplify that both of these assumptions are inherently dangerous and, particularly in the second case, incorrect.

Risk allocation

The appropriate allocation of risk in project agreements is fundamental to negotiations between the project company and its contractors. Risks generally fall into the following categories:

  • Risks within the control of the project company.
  • Risks within the control of the contractor.
  • Risks outside the control of both parties.

The negotiation of the allocation of many of the risks beyond the control of the parties, eg latent site conditions and change of law, is usually very detailed so that it is clear which risks are borne by the contractor. The same approach should be adopted in relation to the risks arising from events of force majeure.

Operation of force majeure clauses

There are two aspects to the operation of force majeure clauses:

  • The definition of force majeure events.
  • The operative clause that sets out the effect on the parties' rights and obligations if a force majeure event occurs.

Definition

The events that trigger the operative clause must be clearly defined. Given the common law meaning of the term force majeure is not certain and is open to interpretation of the courts, it is in the interests of both parties to ensure that the term force majeure is clearly defined.

The preferred approach for a project company is to define force majeure events as being any of the events in an exhaustive list set out in the contract. In this manner, both parties are aware of which events are force majeure events and which are not. Clearly, defining force majeure events makes the administration of the contract and, in particular, the mechanism within the contract for dealing with force majeure events simpler and more effective.

Operative clause

An operative clause will act as a shield for the party affected by the event of force majeure so that it can rely on that clause as a defence to a claim that it has failed to fulfill its obligations under the contract.

An operative clause should also deal specifically with the rights and obligations of the parties if a force majeure event occurs and affects the project. This means the parties must consider each of the events that they intend to include in the definition of force majeure events and then to deal with what the parties will do if one of those events occurs.

Drafting force majeure clauses

Definition

An event of force majeure is an event or circumstance which is beyond the control and without the fault or negligence of the party affected and which by the exercise of reasonable diligence the party affected was unable to prevent provided that event or circumstance is limited to the following:

  1. riot, war, invasion, act of foreign enemies, hostilities (whether war be declared or not), acts of terrorism, civil war, rebellion, revolution, insurrection of military or usurped power, requisition or compulsory acquisition by any governmental or competent authority
  2. ionising radiation or contamination, radio activity from any nuclear fuel or from any nuclear waste from the combustion of nuclear fuel, radioactive toxic explosive or other hazardous properties of any explosive assembly or nuclear component
  3. pressure waves caused by aircraft or other aerial devices travelling at sonic or supersonic speeds
  4. earthquakes, flood, fire or other physical natural disaster, but excluding weather conditions regardless of severity
  5. strikes at national level or industrial disputes at a national level, or strike or industrial disputes by labour not employed by the affected party, its subcontractors or its suppliers and which affect an essential portion of the works but excluding any industrial dispute which is specific to the performance of the works or this contract.

The list of events to be included in this type of definition is a matter for negotiation between the parties. In general, it is preferable for a project company to have a short list of events as the contractor is the party most likely to be affected by force majeure events. The actual process of negotiating this list clearly identifies the risk allocation between the parties.

Operative clause

An example of an operative clause is:

  1. Neither party is responsible for any failure to perform its obligations under this contract, if it is prevented or delayed in performing those obligations by an event of force majeure.
  2. Where there is an event of force majeure, the party prevented from or delayed in performing its obligations under this contract must immediately notify the other party, giving full particulars of the event of force majeure and the reasons for the event of force majeure preventing that party from, or delaying that party in, performing its obligations under this contract and that party must use its reasonable efforts to mitigate the effect of the event of force majeure upon its or their performance of the contract and to fulfill its or their obligations under the contract.
  3. Upon completion of the event of force majeure, the party affected must as soon as reasonably practicable recommence the performance of its obligations under this contract. Where the party affected is the contractor, the contractor must provide a revised program rescheduling the works to minimise the effects of the prevention or delay caused by the event of force majeure.
  4. An event of force majeure does not relieve a party from liability for an obligation that arose before the occurrence of that event, nor does that event affect the obligation to pay money in a timely manner that matured prior to the occurrence of that event.
  5. The contractor has no entitlement and the project company has no liability for:
    1. any costs, losses, expenses, damages or the payment of any part of the contract price during an event of force majeure
    2. any delay costs in any way incurred by the contractor due to an event of force majeure.

In addition to the above clause, it is important to deal appropriately with other issues that will arise if a force majeure event occurs. For example, it is common practice for a contractor to be entitled to an extension of time if a force majeure event impacts on its ability to perform the works. For this reason, force majeure is usually referred to in the extension of time mechanism as an event, which will entitle the contractor to an extension of time.

Another key clause that relates to force majeure-type events is the contractor's responsibility for care of the works and the obligation to reinstate any damage to the works prior to completion. A common example clause is:

  1. The contractor is responsible for the care of the site and the works from when the project company makes the site available to the contractor until 5pm on the date of practical completion.
  2. The contractor must promptly make good loss from, or damage to, any part of the site and the works while it is responsible for their care.
  3. If the loss or damage is caused by an event of force majeure, the project company may direct the contractor to reinstate the works or change the works. The cost of the reinstatement work or any change to the works arising from a direction by the project company under this clause will be dealt with as a variation, except to the extent that the loss or damage has been caused or exacerbated by the failure of the contractor to fulfill its obligations under this contract.
  4. Except as contemplated in clause 3, the cost of all reinstatement works will be borne by the contractor.

Conclusion

It is important for a project company and its contractors to carefully consider the definition of force majeure and how an event of force majeure will affect their rights and obligations under the contract.

The drafting of force majeure definitions and operative clauses (including related clauses) should clearly define the risk allocation between the parties. The above example clauses have been used to demonstrate some options available for dealing with events of force majeure. The specific issues that need to be considered when drafting force majeure clauses will depend on a variety of factors, including the nature and location of the project.

© DLA Phillips Fox

DLA Phillips Fox is one of the largest legal firms in Australasia and a member of DLA Piper Group, an alliance of independent legal practices. It is a separate and distinct legal entity. For more information visit www.dlaphillipsfox.com

This publication is intended as a first point of reference and should not be relied on as a substitute for professional advice. Specialist legal advice should always be sought in relation to any particular circumstances.